The Real Estate (Regulation and Development) Act, 2016

The Real Estate (Regulation and Development) Act, 2016 is an Act of the Parliament of India which seeks to protect home-buyers as well as help boost investments in the real estate industry. The bill was passed by the Rajya Sabha on 10 March 2016 and by the Lok Sabha on 15 March 2016 and received Presidents assent on 25 March 2016.
The Real Estate Act 2016 to establish the Real Estate Regulatory Authority for regulation and promotion of the real estate sector and to ensure sale of plot, apartment or building, as the case may be, or sale of real estate project, in an efficient and transparent manner and to protect the interest of consumers in the real estate sector and to establish an adjudicating mechanism for speedy dispute redressal and also to establish the Appellate Tribunal to hear appeals from the decisions, directions or orders of the Real Estate Regulatory Authority and the adjudicating officer and for matters connected therewith or incidental thereto.
This law vests authority on the real estate regulator to govern both residential and commercial real estate transactions.
This Act obliges the developer to park 70% of the project funds in a dedicated bank account. This will ensure that developers are not able to invest in numerous new projects with the proceeds of the booking money for one project, thus delaying completion and handover to consumers.
This law makes it mandatory for developers to post all information on issues such as project plan, layout, and government approvals, land title status, sub-contractors to the project, schedule for completion with the State Real Estate Regulatory Authority (RERA) and then in effect pass this information on to the consumers.
The maximum jail term for a developer who violates the order of the appellate tribunal of the RERA is three years with or without a fine.
The buyer can contact the developer in writing within one year of taking possession to demand after sales service if any deficiency in the project is noticed.
The developer cannot make any changes to the plan that had been sold without the written consent of the buyer. This puts paid to a common and unpopular practice by developers to increase the cost of projects.
Every project measuring more than 500 square meters or more than eight apartments will have to be registered with the RERA.
For on-going projects which have not received completion certificate on the date of commencement of the Act, will have to seek registration within 3 months. Application for registration must be either approved or rejected within a period of 30 days from the date of application by the RERA. On successful registration, the promoter of the project will be provided with a registration number, a login id and password for the applicants to fill up essential details on the website of the RERA. For failure to register, a penalty of up to 10 percent of the project cost or three years' imprisonment may be imposed
Real estate agents who facilitate selling or purchase of properties must take prior registration from RERA. Such agents will be issued a single registration number for each State or Union Territory, which must be quoted by the agent in every sale facilitated by him.
The current practice of selling on the basis of ambiguous super built-up area for a real estate project will come to a stop as this law makes it illegal. Carpet area has been clearly defined in the law.
Currently, if a project is delayed, then the developer does not suffer in any way. Now, the law ensures that any delay in project completion will make the developer liable to pay the same interest as the EMI being paid by the consumer to the bank back to the consumer.

FREE app 'The Real Estate (Regulation and Development) Act, 2016' will help you understand this new Act whether you are a buyer or promoter of residential project.

App Features

Complete 'The Real Estate (Regulation And Development) Act 2016' in digital format. Doesn't require internet connection to read the act
View data section wise / Chapter wise (Data updated as of 16 March 2016 )
Advanced User friendly Search for any keyword within section/chapter
Ability to view Favourite sections

To Download –

Download on Android Phones
Download on iPhone and iPad
Download on Windows 8.1 and earlier phones
Download on Windows 10 Phone

For any queries, write to us at: contactus@rachittechnology.com
Follow us at:
https://www.facebook.com/RachitTechnology
https://twitter.com/RachitTech
Visit us on web: http://www.rachittechnology.com

मराठी रीती रिवाज- महाराष्ट्रातील सण, देवस्थाने, पूजा, आरत्या आणि बरीच माहिती

मराठी रीती रिवाज या जगाच्या पाठीवर, कुठल्याही ठिकाणचे लोकजीवन खुलून येण्यासाठी मुख्यत्वे करून त्या संस्कृती मधले सण, त्यांचे उत्सव यांचा खूपच मोठा वाटा आहे. दैनंदिन आयुष्य जगताना माणूस हा नेहमीच काहीतरी नवीन घडण्याची वाट पहात होता. माणसाच्या या सतत नाविन्याच्या आणि बदलाच्या ओढीने तो समारंभासाठी निमित्ते शोधत गेला. त्या शोधातूनच सणवारांची निर्मिती झाली. हे सण, उत्सव नेहमीच सर्वाना एकत्र बांधून ठेवण्यात, त्यातून एकात्मता साधण्यात खूपच महत्वाचं कार्य करत आले आहे. आपल्या भारतात आपले सण, उत्सव यांना खूपच महत्व आहे. आपली प्राचीन भारतीय संस्कृती हि नेहमीच अध्यात्माशी निगडित होती. भारतातील तेहतीस कोटी देव, त्यांच्याशी निगडीत असलेल्या पौराणिक कथा, निसर्गात सतत घडणारे बदल, ऋतुमान या सर्वांशी सांगड घालून विविध सणवार यांची निर्मिती झाली. जीवनाला अध्यात्म , भक्तिभावाचा स्पर्श देण्यासाठी सर्व सण उत्सवांना देवकल्पना , पौराणिक कथा-कल्पनांची जोड दिली गेली. विशिष्ठ देवतेचं अधिष्ठान , श्रद्धा , भक्तिभाव , पूजा , व्रत , नैवेद्य इत्यादींची जोड दिल्यामुळे सण धार्मिक...

HOW MOBILE APP IS HELPFUL IN LEARNING LAW ?

Law App - A self-learning platform for Law . Technology has completely transformed our daily life in a best possible way. ‘ Mobile Phone ’ is a great example of such technology. With this Mobile, we can do so many activities, which were hard to believe few years back. In fact today’s generation prefers anything and everything handy i.e. on Mobile, because it is faster n absolutely easy to use. Majority of the businesses/sectors now use Mobile technology to keep pace with the highly competitive market. Mobile technology’s role in educational area is also very vital. Similarly entry of this technology in Legal space has very bright future. WHY YOU NEED A ‘LAW APP’ – THE LAW LEARNING APP : Average cost of Law book is bit expensive. Over the period of time these books needs to be updated & purchased again and again. These books are heavy & expensive as well. So, there has to be a better solution. That's where Rachit Technology steps in. Smart P...

Unique Facts on Aadhaar number And Aadhaar (Targeted Delivery of Financial and Other Subsidies, Benefits and Services) Act, 2016

Unique Facts on Aadhaar number And Aadhaar (Targeted Delivery of Financial and Other Subsidies, Benefits and Services) Act, 2016 Aadhaar is an individual identification number issued by the Unique Identification Authority of India (UIDAI) on behalf of the Government of India to individuals for the purpose of establishing the unique identity of every single person. Unique Identification Authority of India (UIDAI) is responsible for the processes of enrolment and authentication of Aadhaar Card under Aaadhaar Act, 2016. Its objective is to collect biometric and demographic data of residents, store them in a centralized database. First Aadhaar number was launched in Maharashtra in the village of Tembli, on 29 September 2010. Ranjana Sonawne: 782474317884 become the first Indian to get the (UID) number (termed as Aadhaar) Each resident of India will receive 12-digit unique identify number called as Aad...

Hidden Benefits of Crossword Puzzle

Crossword Puzzles are extremely entertaining. But very importantly, it is more than just a pass time activity. Since 1913, Crossword Puzzles have changed the way people utilize and enjoy words. Since then, the researchers are intensely working out to find the benefits of Crossword Puzzles. Being a boredom buster Crossword Puzzles are actually beneficial for our mental health. Many studies have shown the positive effects of Crossword Puzzles on one’s brain. It improves memory and brain function. It is also very much helpful in early Dementia. It helps in improving verbal skills, problem solving, deep thinking and productivity as well. Crossword Puzzles challenge us, as well as they help us to relax. This shift in consciousness comes with many benefits….... Though it is a great way to pass the time, let’s see what the Crossword Puzzles are good for and how it adds value to your life. Special Benefits of Crossword Puzzles – Improves Vocabulary Crossword Puzzles provide great educational o...

Internet Of Things

Internet of Things It’s all started back in 1960’s when internet started to get in shape. Advanced Research Projects Agency Network (ARPANET) was one of the world's first operational packet switching networks, the first network to implement TCP/IP, and one of the progenitors of what was to become the global Internet. The World Wide Web ("WWW" or simply the "Web") is a global information medium which users can read and write via computers connected to the Internet. Sir Timothy John "Tim" Berners-Lee best known as the inventor of the World Wide Web in early 1990’s. Internet continue to evolve, today it is mainly used for communication between 2 humans or also known as H2H (Human to human communication). It currently dominated by emails, chat services, various messengers, websites, shopping portals, entertainment websites. Today there are billions of devices that are connected to internet processing more than petabytes of data. So important...

How Mobile App is helpful in preparing for Competitive Exams?

Competitive Exam Preparation – Mobile App (One stop solution) Technology has completely transformed our daily life in a best possible way. ‘Mobile Phone’ is a great example of such technology. With this Mobile, we can do so many activities, which were hard to believe few years back. In fact today’s generation prefers anything and everything handy i.e. on Mobile, because it is faster n absolutely easy to use. Majority of the businesses/sectors now use Mobile technology to keep pace with the highly competitive market. Mobile technology’s role in educational area is also v ery vital. So, entry of this technology in Competitive Exam Preparation has very bright future. Why you need a ‘Competitive Exam Preparation’ Mobile App: In this extremely competitive world, students have to appear for some competitive exam or the other. Competition in the entrance exams for every sector such as Engineering, Medical, Civil Services, Management etc. is growing at a fast rate, so every aspirant ...

How to Monitor Your Data Usage?

How to Monitor Your Mobile Data Usage? App to monitor your Internet ( 4G/3G/Edge/GPRS/Wifi ), Phone calls ( Incoming/outgoing ) & Call History reports. Worried about phone usage? Want to know total time spend on phone calls? Who is your frequent caller? Surprised by huge phone bill generated at end of the month? Try Phone Usage Monitor , a complete offline phone call and Internet usage monitor tool. Key features of ' Phone Usage Monitor ' - - Track your phone usage real time to avoid extra charges on your bill - View your Wifi and Internet Usage - Track historical data to understand your calling patterns - Detail reports as per your billing cycle - Intuitive reports available at single click - Generate Customized Reports - Share and print your report - No Internet connection required - Progress bar on top ( marked in green/ yellow/ red color ) displays current data/phone usage Once downloaded, the device doesn't need Internet conn...

How Technology is Revolutionizing Legal research: An Insight into the Law App

The legal field is one that has traditionally been slow to adopt new technologies. However, in recent years, there has been a growing trend of technology being used to revolutionize legal search. There are a number of ways in which technology is making legal research more accessible and efficient. For example, online databases make it possible for people to access legal research materials from anywhere in the world. Mobile apps allow lawyers and other legal professionals to research on the go. And artificial intelligence is being used to automate tasks, such as document review and research. Technology is also helping lawyers to be more productive. By automating tasks, lawyers can free up time to focus on more strategic and creative work. Additionally, technology is making it possible for lawyers to collaborate with colleagues and clients remotely. This can save time and money, and it can also improve communication and efficiency. Technology is improving the quality of leg...

How I spend 5000$ in AWS in less than 24 hours

How did it happened? I develop EdTech solutions , mainly mobile apps. I have mobile app “ Competitive Exam Preparation ” available on Android and iOS platform. It is an Entrance Exam Preparation app for AIIMS MBBS, CAT, CLAT-UG, CA CPT, GK, GEP, GATE, JEE-Main, MHT-CET, NDA & NA and NEET exam. It has vital questions from previous year’s papers. It is a free and easy to use educational app, containing 13000+ wide collections of MCQ with answers. Many users of the app use this app for government exam preparation. One of the user asked for support of this app in regional language, primarily user asked support for “ Hindi ” language. Research So I started doing research on tools that will help me to convert English MCQs to Hindi. First thing I looked at was Google Translate https://translate.google.co.in/ It was fast and accurate Next I looked at Amazon Translate https://aws.amazon.com/translate/ Looked at batch translation job page and found it super easy...

Rachit Technology

Search This Blog